Terms and Conditions

Terms and Conditions for Ridgeline Contractors NW

Last Updated: Oct 24-2024

Welcome to Ridgeline Contractors NW. By engaging our services, you agree to the following terms and conditions. Please read them carefully.

1. Scope of Services

Ridgeline Contractors NW (hereafter referred to as “the Contractor”) offers a variety of contracting services, including but not limited to construction, remodeling, and repairs. The specific scope of work will be outlined in the project proposal and agreed upon by both parties before work commences.

2. Licensing and Insurance

The Contractor is fully licensed and insured in the State of Washington. Proof of licensing and insurance can be provided upon request. The Contractor adheres to all state regulations and safety standards.

3. Estimates and Payments

Estimates: All estimates provided are subject to change based on project specifications, material costs, and labor rates. A written estimate will be provided before any work begins.
Payments: Payment terms will be outlined in the project proposal. Typically, a deposit is required prior to the start of work, with the balance due upon completion. Acceptable forms of payment include cash, check, and credit card.

4. Change Orders

Any changes to the original scope of work must be documented in a written change order, which will outline the adjustments to the project and any associated costs. Work will not commence on changes until the change order is approved by both parties.

5. Timeline and Delays

While the Contractor strives to complete projects within the agreed timeline, unforeseen circumstances (e.g., weather, supply chain issues) may cause delays. The Contractor will communicate any delays promptly and work to minimize the impact on project completion.

6. Warranties

The Contractor provides a warranty on workmanship for a period of [insert warranty period, e.g., one year] from the date of project completion. This warranty does not cover damage caused by misuse, abuse, or natural wear and tear.

7. Liability

The Contractor is not liable for any indirect, incidental, or consequential damages arising from the services provided. The Contractor’s total liability for any claims related to the work shall not exceed the total amount paid by the client for the project.

8. Client Responsibilities

Clients are responsible for providing access to the project site, securing necessary permits (if applicable), and ensuring that all utilities are available and operational for the duration of the project.

9. Dispute Resolution

Any disputes arising from these terms and conditions or the services provided shall be resolved through mediation before resorting to arbitration or litigation. Both parties agree to engage in good faith efforts to resolve disputes amicably.

10. Governing Law

These terms and conditions shall be governed by the laws of the State of Washington. Any legal action or proceeding arising from these terms shall be brought in the appropriate court located in [insert relevant county], Washington.

11. Amendments

The Contractor reserves the right to amend these terms and conditions at any time. Clients will be notified of significant changes. Continued use of the Contractor’s services after amendments signifies acceptance of the updated terms.

12. Contact Information

For any questions regarding these terms and conditions, please contact:

Ridgeline Contractors NW
1320 26th St NW #13
Auburn, WA 98001

253-447-7606
[email protected]